工程开工与竣工日期争议及其确定
(1.东南大学土木工程学院项目管理研究所, 江苏 南京 210096,2.东南大学法学院工程法研究所, 江苏 南京 210096)
- 文献要素
-
[摘 要] 通过案例来阐述承包合同双方当事人对开工日期及竣工日期常见的争议,并根据相关法律和示范文本的规定以及工程实务界和法院对开工和竣工日期之相关见解,论述如何确定这两个时点。最后提出了几点建议,以期对工程管理和法律工作人员有所助益。[关键词] 开工日期;竣工日期;争议;确定Abstract: Based on some typical cases, the common conflicts and disputes about commencement date and time for completion of the two parties are stated, then this paper discusses the determination of the two time points according to related laws, model contract and the opinions of engineering practitioners and court. Finally it gives some suggestions in order to be helpful for the project management and legal staff.Key words: commencement date; time for completion; dispute; determination[参考文献][1]David Arditi, Thanat Pattanakitchamroon. Analysis methods in time-based claims[J]. Journal of Construction Engineering and Management,2008(4):242-252.[2]J. Cletus Goetz II, G. Edward Gibson Jr., F, Construction Litigation. U.S. general services administration,1980-2004[J].Journal of Legal Affairs and Dispute Resolution Engineering and Construction, 2009(2):40-46.[3]最高人民法院民事审判第一庭.最高人民法院建设工程施工合同司法解释的理解与适用[M].北京:人民法院出版社,2004:135.[4]王伯俭.工程契约法律事务[M].台湾:元照出版公司,2008:40-41.[5]FIDIC.土木工程施工合同条件应用指南[M].张水波,等,译.北京:航空工业出版社,1997.(编辑 吴颖)建筑经济,2010(10):102-105