逾期违约金条款及其相关争议分析
(1.河南建筑职业技术学院工程管理系, 河南 郑州 450064;2.江苏省电力设计院技术经济部, 江苏 南京 211102;3.东南大学工程法研究所, 江苏 南京 210096;4.东南大学建设与房地产系, 江苏 南京 210096)
- 文献要素
-
[摘 要] 有关逾期违约金争议是较为常见的工程施工合同争议类型。本文以相关法律、司法解释、标准合同范本和法院相关判决为基础,对逾期违约金条款及其争议进行分析和讨论,并对承包商如何防范逾期违约金风险提出建议,以期对工程合同管理实务工作人员和相关工程专业人士更加深入理解工程施工合同中逾期违约金问题有所帮助。[关键词] 逾期违约金;施工合同;风险;争议Abstract: The dispute of liquidated damage for delay(LAD) is not uncommon in construction and engineering. This paper demonstrates the typical and different types of LAD clauses and in-depth analysis of their disputes based on relevant law and judicial interpretation, clauses in the standard forms and judicial cases. It is concluded that following a list guidelines will greatly helpful for contractors effectively avoiding the risk of high LAD. And professionals in the field of construction management will increase understanding of LAD in construction contract from this study.Key words: liquidated damage for delay; construction contract; risk; dispute[参考文献][1]韩世远.合同法[M].3版.北京:法律出版社,2011:656.[2]江平.民法学[M].2版.北京:法律出版社,2011:621.[3]王利明,房绍坤,等.合同法[M].北京:中国人民大学出版社,2002:287.[4]廖振江.建设工程合同条款精析及实务风险案解[M].北京:中国法制出版社,2011:192.[5]陈宽山,江伟勤.建设工程施工合同纠纷判解[M].北京: 法律出版社,2010:205.[6]邱闯.国际工程合同原理与实务[M].北京:中国建筑工业出版社,2001:213.建筑经济,2014(3):51-54