您现在的位置:建筑经济>>往期回顾>2022年>第6期>>文献要素
工期争议典型案例分析及防范建议
刘玲北 丁浩珉
(江苏警官学院,江苏 南京 210031)
文献要素
摘要:本文主要采取实证研究的方法,筛选部分建设工程工期争议典型案例,结合相关法律依据及学界研究成果,并将其分为开工日期争议、工程延期争议、工期索赔争议三种类型进行分析。此外,按照建设工程项目管理的流程,从工程招投标、施工合同签订、施工过程管理、竣工验收结算四个环节提出相应的风险防范措施。本文的研究对指导承包人在工程建设过程中防范可能产生的工期风险,以及解决因工期引发的纠纷都有一定的实践价值。
关键词:工期争议;典型案例;防范建议
Abstract:This paper mainly adopts the method of empirical research to screen some typical cases of construction project duration disputes. Combined with the relevant legal basis and academic research results,Divided into three types:Commencement Date dispute,project delay dispute and duration claim dispute. In addition,according to the process of construction project management,corresponding risk prevention measures are put forward from four links:project bidding,construction contract signing,construction process management and completion acceptance settlement. The research of this paper has certain practical value for guiding the contractor to prevent the possible construction period risk in the process of project construction and solve the disputes caused by construction period.
Keywords:construction period dispute;classic case;preventive suggestions
[1] 余春宜,徐伟.固定总价合同的合同价款典型争议分析及防范建议[J].建筑经济,2021(6):29-32.
[2] 余春宜,袁竞峰,徐伟.工期展延分析技术应用情况及建议[J].建筑经济,2021(1):39-42.
[3] 张叮叮.施工总价合同示范文本的调价机制设计[J].建筑经济,2020(2):73-77.
[4] 符饶.J公司监理延期成本控制措施分析[J].建筑经济,2021(S1):204-206.
[5] 李明,编著.最高人民法院建设工程施工合同纠纷案解[M].北京:法律出版社,2020.
[6] 最高人民法院民事审判庭第一庭编著.《最高人民法院新建设工程施工合同司法解释(一)理解与适用》[M].北京:人民法院出版社,2021.
[7] 朱树英、曹珊,编著.《最高人民法院建设工程施工合同司法解释(二)理解适用与实务指南》[M].北京:法律出版社,2019.
建筑经济,2022(06):41-47
下载地址

    你还没注册?或者没有登录?这篇论文要求至少是本站的注册会员才能阅读!

    如果你还没注册,请赶紧点此注册吧!

    如果你已经注册但还没登录,请赶紧点此登录吧!